Post covers Arrest Showcause Notice Penalty In Rera Executions. Can builder be arrested under RERA via showcause Notice or Section 63 Penalty is discussed in detailed. According to Section 63 of the Real Estate (Regulation and Development) Act, 2016, the promoter of a project is liable to pay a penalty of up to 5% of … Read more
This post covers RERA Appellate Tribunal Himachal Pradesh at Chandigarh where appeals from Real Estate Regulatory Authority (HPRERA) Shimla are being heard. The new website link of Himachal Pradesh RERA Authority is this one- https://hprera.nic.in/ The old one is just here for reference- http://www.hprera.in/WebSite/Home Therefore, under Section 43(4) of Real Estate (Regulation & Development) Act, … Read more
Chandigarh UT do have RERA Authority like RERA Punjab Authority and Haryana RERA Panchkula Authority but not that active since there is dearth of Real Estate Projects in Chandigarh. This can be made from the fact that the under the list of projects it shows figure zero. So certainly there is not much use of … Read more
Thinking of buying a property in Tricity, then talking to RERA Expert property advisor is a must. They can guide you well to understand the intricacies of a project when you are investing your hard earned money. Thinks to Consider- 1 Approvals- Valid License Number, upto date approvals from all authorities. Be it Municipal Body, … Read more
Now that you have got order from RERA Punjab Authority but still clueless what to do next. Then this post will guide you what follows after you have won the case from Punjab Real Estate Regulatory Authority be it refund, interest or compensation. I know it is complex and time consuming but that’s a part … Read more
This post is a must for all those interested to buy property/flat/plot in Zirakpur Kharar Derabsssi or we can say District SAS Nagar (Mohali) in general. RERA Punjab Haryana Property Advice Zirakpur Kharar Derabassi for all residents who have questions related to the project from legal angle. RERA Punjab Haryana Property Lawyers will assist you … Read more
Post covers RERA Case After Delivery of Possession wherein complainant alleges builder has done acts in violation of Section 14. Also case pending before High Court Chandigarh. The case was dismissed since the complainant failed to led evidence that showed deficiencies on part of builder. The complaint was filed before the regulatory authority by the … Read more
RERA Punjab Tribunal awarded compensation in non-rera registered property for delay in possession against Tristar Infrastructures plus refund. Judgement Digest: Gurdeep Singh v. Tristar Infrastructures Case Briefing: Complainant Gurdeep Singh booked 2BHK floor and vide flat buyer agreement dated 09.02.2013 Unit no. 33GF. The unit was allotted to complainant in the project Tunis Premium Homes … Read more
RERA Panchkula Case against Omaxe Pvt Ltd wherein interest with compensation awarded for Delay. Let us have the case here titled as: MADAN LAL MUTNEJA V. M/s OMAXE PVT. LTD., 28th April, 2021 Omaxe Pvt Ltd Haryana RERA Panchkula Case Today we are going to talk about the case of Madan Lal Mutneja v. M/s … Read more
Suncity Builders Pvt Ltd Consumer Complaint wherein refund of amount was allowed for delay in possession. SUBHASH MALIK v. SUNCITY BUILDERS Pvt. LTD. A complaint was filed by the complainant, Subhash Malik, against the respondent, Suncity Buildcon Pvt. Ltd., to refund the amount paid by the complainant as the respondent had failed to make the … Read more
The post talks about Primary Estates & Developers Pvt Ltd wherein builder failed to oblige mandate of Section 18 of RERA. Thus held liable to pay interest compensation for contravention. RELIEF CLAIMED U/S18 RERA, 2016 Also Read- CONSUMER COMPLAINT AGAINST PRIMARY ESTATES AND DEVELOPERS Judgement Digest: Sat Prakash Chauhan vs. M/s Primary Estates & Developers … Read more
In this post we will discuss about consumer Complaint against Barnala Builders & Property Consultants wherein the court held that Special limitation periods have been prescribed under Consumer Protection Act, 1986, its Rules 1987 and its Regulations 2005 for speedy disposal of consumer disputes and it is seen that the complainant has not displayed reasonable diligence … Read more
In this post we will discuss about Consumer Complaint against Maya Garden City wherein the court ordered to deliver the possession of flat on payment of any balance payment if due according to the buyer’s agreement, pay penalty @ Rs. 5/- per sq. ft. of the super area from 16.6.2017 per month till the delivery … Read more
In this post we will discuss about M/S Tulip Infratech Pvt. Ltd HRERA case wherein The Authority while perusing the relevant records observed as per clause 6(a) of the Buyer Builder Agreement executed between the parties, complainant-developer has the remedy to cancel the allotment of respondent-allotee after deducting earnest money. Complaint to seek direction against … Read more
In this post we will discuss about Consumer Complaint against Haryana Shahari Vikas Pradhikaran Huda wherein the court directed the respondent to pay compensation to the complainant equivalent to the amount of interest payable on the amount of sale consideration i.e. Rs. 1,02,50,000/- from 29.04.2015 to 21.06.2018 at the rate prescribed in Rule 15 of … Read more
In this post we will discuss about HRERA complaint against Parsvnath Developers wherein the complaints werw allowed and the respondents were directed to allot and deliver the possession of booked plots to the complainants in the project Parsvnath City, Sonipat on payment of balance sale consideration recoverable from them. RERA Panchkula Complaint against Parsvnath. The … Read more
In this post we will discuss about Punjab RERA complaint against RKM Housing Ltd. wherein PRERA after considering all the facts of the matter held that the complainant has undeniably a statutory right for obtaining interest for every month of delay from the respondent at the rate prescribed in Rule-15 of the RERA Rules, 2017. … Read more
In this post we will discuss about Consumer Complaint against Emaar Mgf Land Limited wherein the court ordered to deliver possession of the allotted corner plot along with all the promised facilities as per the FDI guidelines and ‘Completion Certificate’ and to pay the penalty at the rate of ₹50/- per square yard per month … Read more
In this post we will discuss about the detailed procedure for getting back the mandatory deposit amount required for filing an appeal in HREAT. How to get refund of the amount deposited by the Appellant with the Haryana Real Estate Appellate Tribunal As per Section-43(5) of the Real Estate (Regulation & Development) Act, 2016, any … Read more
Complaint for Execution of RERA orders against Omaxe Pvt.Ltd Summary-In this post we will discuss about a complaint that has been filed by the complainant seeking execution of order dated 05.03.2019 passed by HARYANA REAL ESTATE REGULATORY AUTHORITY PANCHKULA COMPLAINT FOR THE EXECUTION OF THE ORDER passed by the HARYANA REAL ESTATE REGULATORY AUTHORITY PANCHKULA … Read more
In this post we will discuss about mutual settlement between parties and memorandum of settlement. Smt. Suman v. M/s Jagran Developer and Anr Complainant Smt. Suman Respondent M/s Jagran Developer In the present case, the complaint was disposed of, in the first hearing itself, through a final order from the concerned authority. The learned Counsel … Read more
In this post we will discuss about Agreement to Sell under The RERA Act, 2016 and various compliances related to this agreement. Whether Agreement to Sell is to be registered as under RERA? Any contract for sale of an immovable property that provides that the sale takes place on terms that is settled between both … Read more
Builder not liable for compensation if delay is by Government Department. In this post we will discuss about the case of Ultratech developers wherein the buyer was granted interest for the period of delay but no compensation was awarded because the respondent was not responsible for delay. Rajat Chawla v. M/s Ultratech Township Developers Pvt. … Read more
This report looks into a judgment of Punjab and Haryana High Court in the matter of a statutory provision contained in the Real Estate (Regulation and Development) Act 2016. The appellant wished that the deposit as stipulated by the provision should be waived off in light of the unique circumstances of his case. However, appeals … Read more
In this post we will discuss about the quasi-retroactive application of the RERA ACT, 2016 and whether it is applicable when the transactions are still in the process even though the sale agreements had been executed before the Act came into force. Judgment Digest: Anjana Goyal and Another vs Sushma Buildtech Ltd. This recent judgment … Read more
Failure to Handover Possession and Deficiency in Service Case against Suncity Buildcom, Haryana RERA. Summary/ intro: The grievance of the complainant is that the respondent charged a huge amount of illegal money, and did not replied to the rectification sought by him. The respondent then transferred the entire project to Suncity Pvt. Ltd. without informing … Read more
On 13th December 2018, in a suit before the Haryana Real Estate Regulatory Authority (HRERA), Panchkula, seeking compensation for delayed possession of the property, The Adjudicating Officer, Anil Kumar Panwar,ruled in favour of the Complainant, thus,awarding him interest on the sales consideration at the rate prescribed in Rule 15 of The Haryana Real Estate (Regulation … Read more
This post is a case digest on Haryana RERA Panchkula Complaint against Samar Estates wherein the project was standstill and no longer near completion. Keeping in the interest of allottees the Haryana RERA Panchkula Authority order State Government and Town Country Planning and Department to see feasibility if they can take over the project and … Read more
This post covers judgment of Haryana RERA Panchkula Complaint against TDI Infrastructure wherein complainant sought refund of money from the project along with interest and delay compensation on account of non-timely delivery of possession. The relief of refund of relief was not accepted but interest of account of delay was awarded to the complainant. This … Read more
This post is a judgment digest of Haryana RERA Panchkula Complaint against Piyush Buildwell wherein the builder demanded higher amount for conveyance deed which was not as per agreed terms of builder buyer agreement. Hence court directed to take reasonable amount for getting conveyance deed done. Also Read- Execution of Rera Panchkula Orders In combine … Read more
This post is a judgment digest of Haryana RERA Panchkula Complaint Ultratech Township Developers Pvt Ltd which was dismissed by Adjudcating Officer (AO) Panchkula since the matters stands finalized by RERA Authority and no appeal was preferred. Thus the court decided the same matter cannot be reopened again by applicant at this point of time. … Read more
Basic overview of the Article. This article is basically written for the remedies which a Homebuyers have when there rights are violated. Earlier homebuyers were facing a lot of problems relating to the purchase of the properties from builders or developers. There were trapped in the burden of interest in a hope of buying home … Read more
Real Estate Regulation Act, 2016 Punjab Haryana Chandigarh Brief Real Estate Regulation Act was passed by the Parliament in the year 2016, but was implemented in the year 2017. This act comprises of 92 sections. RERA is also know as Real Estate (Regulation and Development) Act. This act was basically brought into force to protect … Read more
In this post, we bring you a judgment digest of a case of Punjab RERA Complaint against Country Colonizers Private Limited for delay in possession and interest on the delay period as per RERA terms before Real Estate Regulatory Authority Punjab (Form M). This would give fair idea to complainants before making their complaints before … Read more
POWERS OF ADJUDICATING OFFICER IN RERA Due to the rapid growth of the Indian economy and the continuous migration of people from rural to urban areas, the need of housing increased at a rapid pace. This shift had a positive effect on the Real Estate sector, and with the continuous growth in the real estate … Read more
There are many instances where Builders unilaterally cancel the allotment of unit and forfeit the money of home buyer. The said practise of Builders has been done to cover up delay in possession and then they except home buyers to continue paying future payments. Haryana Real Estate Regulatory Authority, Gurugram in notification dated 05.12.2018 clearly … Read more
Here in this post, we will cover quick facts about Haryana RERA Panchkula Authority and Punjab RERA Authority at Chandigarh. Both these authorities are working stead fast to solve the problems of homebuyers in the region be it delay in possession, use of poor construction material, cancellation of unit, non-settlement of account books, lack of … Read more
A lot has changed in the Real Estate Sector of India from May 1, 2017 which is when the RERA Act came into force for the state of Haryana. It is only for the benefit of home buyers and consumers that there are two Real Estate Regulatory Authorities in Haryana. One at Gurugram covering all … Read more
In Gurbaksh Singh vs ABW Infrastructure Pvt. Ltd , the HRERA Panchkula Authority has held that TCP is duty bound to ensure completion of licensed projects since based on their assurance and necessary sanctions and approvals , homebuyers put their hard earned money into the project . In this particular case, Director is directed to … Read more
Settled- Getting completion certificate after coming in of RERA rules doesn’t mean that you are exempted. Controversy– In a major blow to developer raising questions of maintainability of complaint before RERA Authority on grounds of getting completion certificate after coming in of provisions of RERA rules, authority held complaint is maintainable and project is under the … Read more
Compliance of RERA Authority’s orders and its statutory obligation is a must under the RERA Act. Defiance of orders of Panchkula-RERA authority has caused builder Parasvnath fined with Rs 5 lakh for non-compliance. Also see- RERA OR CONSUMER FORUM? The Haryana RERA Authority as per act asked builder Parasvnath to maintain an escrow account to manage … Read more
Call Us